ISBEE Set-Aside: Exercise Equipment for the Great Plains Area IHS Youth Regional Treatment Centerview on SAM.gov

**AMENDMENT ONE (1) ADDS QUESTIONS AND ANSWERS TO THE SOLICITATION. THE SUBMISSION DEADLINE IS NOT CHANGED.** Combined Synopsis — Solicitation 75H70626Q00233 The Aberdeen Area Indian Health Service (IHS) is soliciting quotations for the purchase of commercial-grade fitness equipment, including delivery, assembly, installation, operational verification, orientation, and warranty documentation, for the Great Plains Area Youth Regional Treatment Center (YRTC), 12451 SD-1806, Mobridge, South Dakota 57601. The acquisition is issued as RFQ 75H70626Q00233 and is a 100% Indian Small Business Economic Enterprise (ISBEE) set-aside under the Buy Indian Act. The applicable NAICS code is 423910. Requirement The contractor will furnish and install six pieces of commercial fitness equipment, or technically acceptable equal products: | 1 | Inflight Fitness Multi Bicep/Tricep, 150-lb stack, CT-MBTS-150 | 2 | Inflight Fitness Multi Inner/Outer Thigh, 150-lb stack, CT-MIOS-150 | 3 | Inflight Fitness Multi Seated Leg Extension/Leg Curl, 250-lb stack, CT-MSECS-250 | 4 | Inflight Fitness Multi Press, 250-lb stack, CT-MPSS-250 | 5 | Inflight Fitness Multi Leg Press, 250-lb stack, CT-MLPS-250 | 6 | Muscle D Commercial Stair Climber with LED Console, CC-SC-LS-B Shipping is identified separately as Item 7. The identified brands/models establish the type of equipment contemplated rather than an absolute brand restriction. Equal products may be offered if they satisfy the solicitation's salient functional and performance characteristics. Reference-product dimensions and weights are principally for delivery and installation planning and are not exact design restrictions unless necessary to fit the Government-designated installation area. Quantities are firm requirements. Delivery and Performance Performance begins upon award. The contractor must complete delivery, installation, operational verification, orientation, and submission of warranty documentation within 30–60 calendar days after award, unless the award establishes another completion date or the Contracting Officer subsequently changes it in writing. Contractors are required to promptly advise the Contracting Officer of anticipated commercial supply-chain delays. Pricing is to be FOB Destination and must include packaging, handling, shipping, and delivery. Unit prices are described as all-inclusive of costs associated with performance. Competition and Eligibility Competition is limited to concerns that qualify as both an Indian Economic Enterprise and a small business concern . Firms that do not meet both requirements will not be considered. Offerors must submit the required Indian Economic Enterprise Representation Form and represent that they meet the IEE definition and will continue to meet it throughout contract performance. Offerors must also have an active SAM.gov registration and current UEI before awar…